top of page
Diamond Blinds Logo

Terms Of Service & Privacy Policy

​

​

About this policy
Diamond Blinds Pty Ltd (ACN 671 123 372) (“Diamond Blinds”) is committed to protecting Personal Information we collect from you pursuant to the Privacy Act 1988 and the Australian Privacy Principles. “Diamond Blinds's website” means any of Diamond Blinds’s website including https://diamondblinds.com.au “Personal Information” means your name, email address and telephone number. “You” means the user that accesses Diamond Blinds’s website and extends to the entity which employs the you to research and order the goods. Diamond Blinds sells and installs Outdoor Blinds, Plantation Shutters, Aluminium Louvres and Roller Shutters to customers. Diamond Blinds respects your right to privacy and is committed to safeguarding the privacy of our customers. This policy explains how we deal with your Personal Information.

Why does Diamond Blinds collect your Personal Information?
We collect your Personal Information to enable us to sell our goods and services to you. Diamond Blinds may also use this information to promote or market its, or its related business’, current and future goods to you.

​

What Personal Information does Diamond Blinds collect?

The types of information Diamond Blinds collects include:
your name, email address details and non-personally identifiable information, including but not limited to browser type, version and language, operating system, pages viewed while browsing the Site, page access times and referring website address. This non- personally identifiable collected information is used to assess visitor traffic, trends and delivering personalised content to you on Diamond Blinds’s website.

 

Why do you collect such personal information?
We collect such Non-personal and Personal Information for the following purposes:

  • To provide and operate the Diamond Blinds Services;

  • To provide our Users with ongoing customer assistance and technical support;

  • To be able to contact our Visitors and Users with general or personalized service-related notices and promotional messages;

  • To create aggregated statistical data and other aggregated and/or inferred Non-personal Information, which we or our business partners may use to provide and improve our respective services;

  • To comply with any applicable laws and regulations.

 

How does Diamond Blind’s store, use, share and disclose personal information?
Diamond Blinds does not collect any Personal Information it does not need. Our company is hosted on the Wix.com platform. Wix.com provides us with the online platform that allows us to sell our products and services to you. Your data may be stored through Wix.com’s data storage, databases and the general Wix.com applications. They store your data on secure servers behind a firewall. 

 

Your personal Information will be collected:

When you request information from or submit inquiry forms with Diamond Blinds; and when you access or request information via Diamond Blind’s website; and through the use of ‘cookies’, which is an element of data that a website can send to your internet browser, which may then store it on your computer system. Diamond Blind’s website uses cookies so that Diamond Blind’s can better serve you with tailored information when you return.

​

Diamond Blinds may use your Personal Information to:


Manufacture and provide you with goods ordered; Conduct research (including but not limited to client surveys) concerning Diamond Blinds current and future goods; and engage in marketing activities, such as: Deliver target marketing, send you marketing
communications to inform you about our events or affiliated events, and provide you with promotional offers tailored to you;
Our direct marketing list may be operated by software and servers located overseas and your Personal Information may be sent overseas as part of our marketing; and We may also make you aware of new and additional goods and opportunities available to you. You may
opt-out of our marketing communications at any time by clicking unsubscribe at the bottom of your received email.

​

What if you don't provide your Personal Information?

If you can't or won't provide Diamond Blind’s with the Personal Information it reasonably requires, Diamond Blind’s may be unable to provide you the goods you wish to purchase.

Diamond Blind’s will only use your Personal Information for the purpose of direct marketing and to sell your requested goods to you.

That includes where we collected the Personal Information from you and you would reasonably expect the information to be used for direct marketing. In all other circumstances we will only use your Personal Information with your consent or where it is impracticable to obtain that consent. In all direct marketing correspondence sent to you we will give you the opportunity to "opt out" of receiving any further marketing correspondence. Norman will not spam, sell or rent your Personal Information to any party.

​

Third party disclosure
We may disclose your personal information:
To any of our related entities, employees, officers, insurers, professional advisers, agents, suppliers, sponsors, government agencies or subcontractors insofar as reasonably necessary;
To third parties who help us analyse the information we collect so that we can administer, support, improve or develop our business and the services we provide to you; To any other person with your consent (express or implied).

The Internet is not a secure environment. Diamond Blinds takes reasonable steps to ensure the information you provide to Diamond Blinds is, to the extent reasonably possible, secure and protected from risks such as loss, unauthorised access or use, destruction, modification or disclosure.

 

Diamondblinds.com.au website may contain links to other websites. Diamond Blinds is not responsible for the privacy practices of those other websites. Nor is Diamond Blind’s responsible for the content and information presented on those sites.

 

In the event that the Diamond Blinds business has a transfer of ownership, goes out of business or in the unlikely event files for bankruptcy, we would include data among the assets transferred to any parties who acquire us. You acknowledge that any such transfer may occur and that any parties who acquire us may continue to use your information according to this policy.

Diamond Blind’s reserves the right to change this Privacy Policy from time to time. This Privacy Policy was last updated in January 2024

 

Acceptance of this Privacy Policy
By proceeding to use Diamond Blind’s website, you hereby acknowledge acceptance of the terms of this Privacy Policy. If you do not agree with any aspect of this Privacy Policy, you should immediately cease using Diamond Blinds’s website. If you feel more comfortable sharing information in an alternative way, feel free to call us or send us and email instead at info@diamondblinds.com.au

 

Terms and Conditions of Sales Effective: June2024

​

GENERAL *Product warranty is not transferrable and only the original purchaser of the products can make a claim under its warranty. 1. Upon acceptance of these terms, a binding contract is entered into between the customer and Diamond Blinds and Shutters not withstanding Diamond Blinds right of non-acceptance due to errors and omissions. 2. Quotations provided by Diamond Blinds valid for 30 days and may be subject to change after that time. Accepted orders are subject to checking at Diamond Blinds office where Diamond Blinds the right of non-acceptance. 3. Completion date is an estimate only and subject to material availability. No responsibility will be accepted for delays as stated in clause 20. 4. Customer to make access to the works available between 7.00am to 4.00pm Monday to Friday or as otherwise agreed. 5. Customer accepts that any powder coat colours and brand stated on this quote are as per the customers selection and that Diamond Blinds no responsibility for shade variations. 6. Diamond Blinds accepts no responsibility for material variations such as colour, grain, rippling, shrinkage or changes in length and Diamond Blinds not be liable in any way for loss or damage suffered consequently thereof. 7. Whilst every attempt will be made by Diamond Blinds ensure that the products sold and delivered match samples or products on display in showrooms, any minor or immaterial variation or change in colour or grain between the sample and the goods delivered shall not entitle the customer to reject the goods nor to claim any compensation for such variation or change. 8. Diamond Blinds to achieve the highest standard possible in the manufacture and installation of products which have been purchased and all work will be carried out as directed by Diamond Blinds specific instructions are written on this agreement, or actual written specifications are given to Diamond Blinds the customer at point of sale. 9. Customer acknowledges that Diamond Blinds are not qualified colour consultants or interior decorators – any suggestions or recommendations are their opinions only and the customer takes responsibility for the choice of materials or products ordered. 10. The acceptable standard for imperfections on the final job is – if it is visible with the naked eye, in natural daylight at a distance of 1.2 metres, it is not acceptable. If it is not visible with the naked eye, in natural daylight, at a distance of 1.2 metres it is acceptable. Terms of payment 11. Deposit A 50% deposit is required upon acceptance of the quote and placement of the order. This deposit is non-refundable if you cancel the order after work has commenced on your products. 12. Final Payment The final 50% payment is due on the day of completion of the installation. Payment must be made in full before the installers leave the premises. We accept cash, credit card, debit card, or EFTPOS. 13. Late Payment Fees A late fee of 2% per month will be applied to any outstanding balance after 14 days from the due date. We reserve the right to take legal action to recover any outstanding debts, and you will be liable for all associated costs, including legal fees. 14. Retention of Title You acknowledge that the goods and services we supply remain our property until you pay for them in full. If you default on any terms of this agreement, including payment, we have the right to repossess the goods without notice. You authorise us or our representatives to enter the premises where the goods are located to reclaim them. We will not be responsible for any costs, losses, or damages resulting from repossessing the goods. 15. Progress Payments for Delayed Delivery/Installation If you are not ready to receive or have the goods installed after six weeks from the manufacture date due to reasons on your end, you may be required to pay a progress payment of up to the total value of the purchase price or as otherwise agreed upon in writing. 16. Customer Refusal of Acceptance or Installation If we advise you that your ordered products are ready for installation and you refuse to accept them or make arrangements for installation within a reasonable timeframe, or if we cannot contact you after reasonable efforts, the remaining balance will become due immediately. We can treat the remaining amount as a judgment debt enforceable without further action. 17. Service of Notices You agree that service of any notices or Court documents may be affected by forwarding them by pre-paid post or facsimile to your last known address or fax number. 18. The customer agrees not to hold Diamond Blinds responsible for any delays with supply or installation and agrees not to demand any compensation, whether monetary or otherwise. The customer also agrees not to withhold payment if, for any reason, a minor part of a customer’s order is delayed. 19. The customer agrees that service of any notices or Court documents may be affected by forwarding same by pre-paid post or facsimile to the last known address or facsimile number of the customer. 20. Force Majeure Diamond Blinds not be liable for any failure or delay to supply, deliver, or install the products where such failure or delay is wholly or partly due to any cause or circumstance whatsoever outside the reasonable control of Diamond Blinds. This may include, but is not limited to, natural disasters, acts of war or terrorism, labour disputes, or material shortages. Product Installation 21. Customer Access Customers are required to provide suitable access for all installation inside and outside the house before the commencement of the work. This includes removing any obstructions that could interfere with the installation or valuables that could be damaged. If a Diamond Blinds technician encounters any unforeseen difficulty with access or installation due to a customer lack of preparation, the customer agrees to pay for any additional costs that may arise. 22. Asbestos Customers are responsible for advising Diamond Blinds of the presence of any asbestos at the installation address, as disturbing asbestos during installation can be hazardous. 23. Existing Window Treatments Customers are responsible for removing any existing window treatments unless other arrangements are made with the Diamond Blinds Representative at the point of sale. 24. Window Squareness Diamond Blinds products are manufactured to be square. However, some exceptions may exist. Diamond Blinds cannot accept responsibility for windows that are out of square, as this is a building issue, not a product issue. 25. Damage During Installation Diamond Blinds will not be responsible for any damage that may occur at or after the installation of a product or accessory that requires fixing into materials, including (but not limited to) tiles, carpet, timber flooring, or laminated benchtops. It is important to understand the potential risks of drilling or screwing into these surfaces before installation. 26. Damage to Premises or Interruptions to Services While Diamond Blinds takes great care during installation, the company will not be responsible for any damage to premises or interruption to services where such damage or interruption is a result of circumstances beyond Diamond Blinds control.This may include unforeseen structural issues or encountering pre-existing wiring or plumbing during installation. 27. Corded Blinds and Child Safety Please note that all blinds installed by Diamond Blinds will comply with Australian Child Safety Laws. Guarantee and Warranty 28. Product Suitability and New Condition Diamond Blinds warrants that all products are fit for their intended purpose and are new unless otherwise stated in the contract. 29. Warranty on Defects Diamond Blinds guarantees that all our products will be free from defects in components and manufacturing at the time of installation. This guarantee only becomes effective after full payment has been received. Diamond Blinds will use its best efforts to pass on to the customer the benefit of any guarantees or warranties received from manufacturers for products or parts not manufactured by Diamond Blinds. Please see our website for more information about specific product guarantees and warranty details. 30. Domestic Use Warranty For domestic use, all supplied goods are guaranteed against faulty materials and workmanship. Diamond Blinds will, at its discretion, repair or replace products or parts thereof that prove faulty. This warranty does not cover damage caused by accidents, misuse, or colour change resulting from solar or other heat sources. If a Diamond Blinds technician determines that a reported defect is not due to faulty workmanship or material, a call-out fee may be charged. 31. Compliance with Laws and Regulations Diamond Blinds warrants that all work will be carried out in accordance with all relevant laws and legal requirements.

bottom of page